Cases & Deals

  • Home
  • Practices
  • Hong Kong contractor arbitrates against developer of residential buildings for unpaid contract price

Share

Hong Kong contractor arbitrates against developer of residential buildings for unpaid contract price

April 2014

Clients Hong Kong contractor

Jones Day represented a contractor in arbitration proceedings against a developer of residential buildings in Hong Kong for the unpaid contract price and the loss and expenses for the delay and disruption to the project schedule. The arbitration is seated in Hong Kong and conducted under the Administered Rules of the Hong Kong International Arbitration Center (HKIAC).

Before sending, please note:

Information on www.jonesday.com is for general use and is not legal advice. The mailing of this email is not intended to create, and receipt of it does not constitute, an attorney-client relationship. Anything that you send to anyone at our Firm will not be confidential or privileged unless we have agreed to represent you. If you send this email, you confirm that you have read and understand this notice.